Transcript Highlights:

• Charleston doing my MBA, back in 2012, we had a professor, and he had up on the board, first day of class
• We had a professor, and he had up on the board, first day of class, had 98%.
• So in 2021, the Legislature enacted into law 5A-824, the subsection just above where this bill is purported
• ...5A-824, the subsection just above where this bill is purported to go, and last summer in August of

Keywords: 994, senate, all

Summary: The committee first approved the previous meeting’s minutes, then took up House Bill 4198, which would require all employers to use E-Verify to confirm new hires’ work authorization. Counsel explained that the bill would add enforcement by the Division of Labor, create tiered penalties including warnings, fines, debarment from state contracts, and possible business license revocation, while also removing criminal penalties tied to hiring unauthorized workers in light of federal law. Members raised extensive concerns about drafting problems, including circular and conflicting language, unclear references to existing verification and recordkeeping provisions, the meaning of terms like “seeks to employ,” and whether the bill could unintentionally apply to babysitters, lawn care, and other casual or household arrangements. Questions also focused on whether the bill would apply to public versus private employers, how compliance would be shown, and how penalties would work for small businesses or employers who never actually hire the person in question. The bill sponsor defended the measure as a straightforward extension of the federally required I-9 process, saying E-Verify is a quick, free online check that helps employers verify work authorization and protects them from liability for unknowingly hiring unauthorized workers. He said the bill was intended to be mandatory, not permissive, and argued that it would help law-abiding employers compete fairly. After the questioning, the committee rejected a motion to table the bill and instead sent House Bill 4198 to a seven-member subcommittee to clean up the drafting, resolve inconsistencies, and review the penalties and scope of the measure. The subcommittee was directed to meet the next morning and report back quickly. The committee then moved to House Bill 4710, with an amendment that would require a person to be registered with a political party or as an independent 210 days before filing a certificate of candidacy. Counsel explained that the bill is aimed at preventing candidates from switching parties after losing a primary and then running as independents in the general election. Members discussed how the 210-day requirement would interact with both primary and general election filing deadlines, and the Secretary of State’s office clarified that the measure would affect candidates who change affiliation shortly before filing. The discussion continued with testimony from the Secretary of State’s general counsel about how the bill would operate in practice, but no final action on the bill was taken in the portion of the meeting provided.

Transcript Highlights:

• That's the meaning of paragraph 5A in RSA 72:23.
• You know, similar mission or goal shall be exempt from taxation if the language in 5A is not clear.
• if if the shall be exempt from taxation if if the language<04:14:06.319> in<04:14:06.560> 5A
• is not clear so I argue that the in 5A is not clear so I argue that the words<04:14:14.080> in
• In semiannual tax bill communities, folks receive it directly by first-class mail from the U.S.

Keywords: 1189, house, all

Transcript Highlights:

• , Greg Abbott, governor of the state of Texas, by the authority vested in me by Article 3, Sections 5A

Transcript Highlights:

• I'm State Representative Christa Kuden from House District 5A, and I'm here to talk to you about a bill

Keywords: 1183, house

Transcript Highlights:

• 2011 just adds detention contracted employees of county juvenile facilities to the list of protected classes
• Currently, we have it on page 6, line 5. mailed by first-class mail to the last address or shall be sent
• So, if the email didn't go through, we'd still have the backup of first-class mail with a with return

Bills: SB1638, SB504, SB2072, SB1283, SB1216, SB1655, SB2011, SB1643, SB1446, SB1256, SB1258, SB1441, SB1224, SB1448, SB1496, SB1597, SB1621, SB1827, SB2066, SB2104

Keywords: Governmental Tort Claims Act, liability limits, claims, medical negligence, tort reform, state liability, public health, claims adjustment, compensation limits, fraudulent conveyance, property rights, title theft, real estate law, law enforcement, probate procedure, agent residency, legal process, statutory language, gender neutral, SB 1216

Transcript Highlights:

• SB 875 establishes a Class B misdemeanor if a chief administrator of an executive school district campus
• What it's doing now is adding a misdemeanor, a Class A misdemeanor, which includes 80 days in jail and
• And a Class B misdemeanor as well. I forgot what the days are, but it's like a $2,000 fine.
• This bill seeks to put in the penalties, as I stated earlier: Class A, which is a year in jail and a
• $4,000 fine; Class B, 180 days in jail and a $2,000 fine.

Bills: SB204, SB570, SB735, SB784, SB1207, SB1396, SB1447, SB2392, SB2540, SB747, SB875

Keywords: parental rights, education, school trustees, training, handbook, truancy, attendance policy, chronic absenteeism, school attendance, student absence notifications, parent notification, home visit, attendance officer, truancy court, school district, open-enrollment charter school, student support services, school counselor, principal, administrator

Transcript Highlights:

• Uh, if Christian Academy SGA class. Uh, if Christian Academy SGA class.
• I was in the sixth grade and she class. I was in the sixth grade and she class.
• So we had a spelling class. So we had a spelling class.
• She said, "As I told you she the class. She said, "As I told you she the class.
• I'm talking in front of the class. Her I'm talking in front of the class.

Bills: SJR 59, SCR 30, SCR 46, SB 31, SB 127, SB 324, SB 401, SB 407, SB 467, SB 482, SB 506, SB 529, SB 584, SB 619, SB 636, SB 646, SB 647, SB 659, SB 715, SB 732, SB 735, SB 771, SB 784, SB 800, SB 801, SB 816, SB 1013, SB 1026, SB 1049, SB 1055, SB 1065, SB 1137, SB 1169, SB 1181, SB 1383, SB 1395, SB 1410, SB 1433, SB 1524, SB 1531, SB 1568, SB 1640, SB 1666, SB 1681, SB 1718, SB 1754, SB 1757, SB 1972, SB 1980, SB 2004, SB 2007, SB 2041, SB 2046, SB 2050, SB 2075, SB 2076, SB 2154, SB 2173, SB 2206, SB 2225, SB 2253, SB 2268, SB 2306, SB 2308, SB 2314, SB 2322, SB 2330, SB 2351, SB 2366, SB 2371, SB 2392, SB 2398, SB 2476, SB 2533, SB 2540, SB 2544, SB 2589, SB 2610, SB 2623, SB 2660, SB 2662, SB 2693, SB 2707, SB 2717, SB 2722, SB 2742, SB 2753, SB 2779, SB 2807, SB 2843, SB 2844, SB 2858, SB 2877, SB 2880, SB 2885, SB 2920, SB 2938, SB 2986, HJR 4, HCR 35, SJR 3, SJR 18, SB 5, SB 260, SB 1786, SB 914, SB 963, SB 1197, SB 1415, SB 1437, SJR 36, SJR 50, SJR 63, SJR 84, SJR 59, SCR 12, SCR 39, SCR 46, SCR 48, SCR 19, SCR 30, SCR 3, SB 2023, SB 1433, SB 2322, SB 2877, SB 407, SB 1718, SB 1395, SB 62, SB 666, SB 847, SB 284, SB 854, SB 1073, SB 810, SB 1505, SB 583, SB 1502, SB 507, SB 1026, SB 1434, SB 1376, SB 1585, SB 1772, SB 2016, SB 1163, SB 619, SB 1122, SB 732, SB 731, SB 397, SB 508, SB 1436, SB 287, SB 261, SB 1882, SB 393, SB 1791, SB 529, SB 209, SB 2429, SB 1999, SB 511, SB 2309, SB 510, SB 2253, SB 584, SB 1085, SB 2314, SB 2046, SB 1975, SB 2717, SB 1262, SB 1524, SB 1137, SB 636, SB 2056, SB 884, SB 517, SB 1200, SB 1410, SB 1845, SB 1863, SB 2681, SB 2200, SB 2199, SB 1757, SB 2050, SB 2458, SB 2201, SB 1055, SB 2660, SB 2662, SB 1065, SB 801, SB 2533, SB 3014, SB 3013, SB 758, SB 647, SB 1721, SB 2268, SB 2366, SB 1013, SB 2797, SB 2371, SB 2383, SB 646, SB 1169, SB 1754, SB 2779, SB 2004, SB 2119, SB 2448, SB 1777, SB 1283, SB 2392, SB 2076, SB 2786, SB 2876, SB 2284, SB 2225, SB 1540, SB 2920, SB 2929, SB 1972, SB 2540, SB 2742, SB 2595, SB 2217, SB 715, SB 2330, SB 1383, SB 500, SB 1640, SB 2001, SB 2080, SB 2722, SB 506, SB 2514, SB 2623, SB 2753, SB 2398, SB 1241, SB 2927, SB 2173, SB 2538, SB 898, SB 467, SB 1449, SB 2529, SB 1531, SB 2846, SB 2476, SB 986, SB 1181, SB 2075, SB 2154, SB 2864, SB 31, SB 2880, SB 1359, SB 2386, SB 771, SB 2844, SB 2550, SB 1351, SB 1423, SB 1931, SB 2245, SB 2589, SB 2707, SB 2807, SB 2351, SB 410, SB 659, SB 816, SB 2776, SB 2693, SB 2580, SB 1980, SB 1886, SB 1234, SB 739, SB 482, SB 456, SB 127, SB 1666, SB 2843, SB 2801, SB 800, SB 2055, SB 784, SB 2986, SB 735, SB 1012, SB 324, SB 2926, SB 2938, SB 2007, SB 2138, SB 1242, SB 2615, SB 1049, SB 2310, SB 1224, SB 2972, SB 1568, SB 2841, SB 2885, SB 3016, SB 2858, SB 2610, SB 2139, SB 1856, SB 2035, SB 2308, SB 2306, SB 2041, SB 1528, SB 1681, SB 1141, SB 2401, SB 2530, SB 2375, SB 547, SB 1266, SB 1373, SB 1467, SB 2069, SB 2269, SB 2480, SB 2544, SB 672, SB 904, SB 2695, SB 2891, SB 2422, SB 2543, SB 1854, SB 317, SB 2539, SB 2532, SB 2925, SB 1250, SB 2082, SB 2203, SB 457, SB 2357, HJR 4, HB 135, HB 1109, HCR 35, HCR 64, SB 2721, SB 243, SB 1285, SB 2568, SB 1959, SB 1442, SB 1454, SB 2520, SB 2541, SB 1708, SB 1237, SB 1844, SB 1586, SB 1, SB 260, SB 31, SB 467, SB 482, SB 647, SB 732, SB 816, SB 1055, SB 1137, SB 1169, SB 2004, SB 2253, SB 2268, SB 2314, SB 2351, SB 2371, SB 2623, SB 2722, SB 2779, SB 2920, HJR 4, SB 407, SB 1395, SB 1433, SB 1718, SB 2322, SB 2877, SB 619, SB 646, SB 1026, SB 2742, SB 2880, SR 443, SR 449, SR 456, SR 460, SR 465, SCR 46, SB 260, SB 3062, HJR 8, HJR 31, HJR 72, HJR 99, HJR 133, HB 29, HB 33, HB 50, HB 107, HB 116, HB 125, HB 140, HB 141, HB 155, HB 171, HB 227, HB 255, HB 363, HB 368, HB 491, HB 609, HB 630, HB 745, HB 767, HB 913, HB 917, HB 1135, HB 1188, HB 1238, HB 1242, HB 1261, HB 1318, HB 1404, HB 1495, HB 1507, HB 1606, HB 1708, HB 1748, HB 1851, HB 1922, HB 2002, HB 2003, HB 2198, HB 2355, HB 2358, HB 2415, HB 2457, HB 2495, HB 2546, HB 2637, HB 2763, HB 2765, HB 2798, HB 2818, HB 3228, HB 3307, HB 4116, HCR 29, SB 1410, SB 3062, HJR 8, HJR 31, HJR 72, HJR 99, HJR 133, HB 29, HB 33, HB 50, HB 107, HB 116, HB 125, HB 140, HB 141, HB 155, HB 171, HB 227, HB 255, HB 363, HB 368, HB 491, HB 609, HB 630, HB 745, HB 767, HB 913, HB 917, HB 1135, HB 1188, HB 1238, HB 1242, HB 1261, HB 1318, HB 1404, HB 1495, HB 1507, HB 1606, HB 1708, HB 1748, HB 1851, HB 1922, HB 2002, HB 2003, HB 2198, HB 2355, HB 2358, HB 2415, HB 2457, HB 2495, HB 2546, HB 2637, HB 2763, HB 2765, HB 2798, HB 2818, HB 3228, HB 3307, HB 4116, HCR 29, SB 1410

Keywords: education funding, Texas State Technical College System, capital projects, infrastructure, higher education, Birding Capital, Matagorda County, wildlife, conservation, Texas Legislature, Texas beef, cattle industry, agricultural heritage, Texas strip steak, economic growth, SB 31, Life of the Mother Act, Texas abortion law, medical emergency, reasonable medical judgment

Transcript Highlights:

• Uh, if Christian Academy SGA class. Uh, if Christian Academy SGA class.
• I was in the sixth grade and she class. I was in the sixth grade and she class.
• So we had a spelling class. So we had a spelling class.
• She said, "As I told you she the class. She said, "As I told you she the class.
• I'm talking in front of the class. Her I'm talking in front of the class.

Bills: SJR 59, SCR 30, SCR 46, SB 31, SB 127, SB 324, SB 401, SB 407, SB 467, SB 482, SB 506, SB 529, SB 584, SB 619, SB 636, SB 646, SB 647, SB 659, SB 715, SB 732, SB 735, SB 771, SB 784, SB 800, SB 801, SB 816, SB 1013, SB 1026, SB 1049, SB 1055, SB 1065, SB 1137, SB 1169, SB 1181, SB 1383, SB 1395, SB 1410, SB 1433, SB 1524, SB 1531, SB 1568, SB 1640, SB 1666, SB 1681, SB 1718, SB 1754, SB 1757, SB 1972, SB 1980, SB 2004, SB 2007, SB 2041, SB 2046, SB 2050, SB 2075, SB 2076, SB 2154, SB 2173, SB 2206, SB 2225, SB 2253, SB 2268, SB 2306, SB 2308, SB 2314, SB 2322, SB 2330, SB 2351, SB 2366, SB 2371, SB 2392, SB 2398, SB 2476, SB 2533, SB 2540, SB 2544, SB 2589, SB 2610, SB 2623, SB 2660, SB 2662, SB 2693, SB 2707, SB 2717, SB 2722, SB 2742, SB 2753, SB 2779, SB 2807, SB 2843, SB 2844, SB 2858, SB 2877, SB 2880, SB 2885, SB 2920, SB 2938, SB 2986, HJR 4, HCR 35, SJR 3, SJR 18, SB 5, SB 260, SB 1786, SB 914, SB 963, SB 1197, SB 1415, SB 1437, SJR 36, SJR 50, SJR 63, SJR 84, SJR 59, SCR 12, SCR 39, SCR 46, SCR 48, SCR 19, SCR 30, SCR 3, SB 2023, SB 1433, SB 2322, SB 2877, SB 407, SB 1718, SB 1395, SB 62, SB 666, SB 847, SB 284, SB 854, SB 1073, SB 810, SB 1505, SB 583, SB 1502, SB 507, SB 1026, SB 1434, SB 1376, SB 1585, SB 1772, SB 2016, SB 1163, SB 619, SB 1122, SB 732, SB 731, SB 397, SB 508, SB 1436, SB 287, SB 261, SB 1882, SB 393, SB 1791, SB 529, SB 209, SB 2429, SB 1999, SB 511, SB 2309, SB 510, SB 2253, SB 584, SB 1085, SB 2314, SB 2046, SB 1975, SB 2717, SB 1262, SB 1524, SB 1137, SB 636, SB 2056, SB 884, SB 517, SB 1200, SB 1410, SB 1845, SB 1863, SB 2681, SB 2200, SB 2199, SB 1757, SB 2050, SB 2458, SB 2201, SB 1055, SB 2660, SB 2662, SB 1065, SB 801, SB 2533, SB 3014, SB 3013, SB 758, SB 647, SB 1721, SB 2268, SB 2366, SB 1013, SB 2797, SB 2371, SB 2383, SB 646, SB 1169, SB 1754, SB 2779, SB 2004, SB 2119, SB 2448, SB 1777, SB 1283, SB 2392, SB 2076, SB 2786, SB 2876, SB 2284, SB 2225, SB 1540, SB 2920, SB 2929, SB 1972, SB 2540, SB 2742, SB 2595, SB 2217, SB 715, SB 2330, SB 1383, SB 500, SB 1640, SB 2001, SB 2080, SB 2722, SB 506, SB 2514, SB 2623, SB 2753, SB 2398, SB 1241, SB 2927, SB 2173, SB 2538, SB 898, SB 467, SB 1449, SB 2529, SB 1531, SB 2846, SB 2476, SB 986, SB 1181, SB 2075, SB 2154, SB 2864, SB 31, SB 2880, SB 1359, SB 2386, SB 771, SB 2844, SB 2550, SB 1351, SB 1423, SB 1931, SB 2245, SB 2589, SB 2707, SB 2807, SB 2351, SB 410, SB 659, SB 816, SB 2776, SB 2693, SB 2580, SB 1980, SB 1886, SB 1234, SB 739, SB 482, SB 456, SB 127, SB 1666, SB 2843, SB 2801, SB 800, SB 2055, SB 784, SB 2986, SB 735, SB 1012, SB 324, SB 2926, SB 2938, SB 2007, SB 2138, SB 1242, SB 2615, SB 1049, SB 2310, SB 1224, SB 2972, SB 1568, SB 2841, SB 2885, SB 3016, SB 2858, SB 2610, SB 2139, SB 1856, SB 2035, SB 2308, SB 2306, SB 2041, SB 1528, SB 1681, SB 1141, SB 2401, SB 2530, SB 2375, SB 547, SB 1266, SB 1373, SB 1467, SB 2069, SB 2269, SB 2480, SB 2544, SB 672, SB 904, SB 2695, SB 2891, SB 2422, SB 2543, SB 1854, SB 317, SB 2539, SB 2532, SB 2925, SB 1250, SB 2082, SB 2203, SB 457, SB 2357, HJR 4, HB 135, HB 1109, HCR 35, HCR 64, SB 2721, SB 243, SB 1285, SB 2568, SB 1959, SB 1442, SB 1454, SB 2520, SB 2541, SB 1708, SB 1237, SB 1844, SB 1586, SB 1, SB 260, SB 31, SB 467, SB 482, SB 647, SB 732, SB 816, SB 1055, SB 1137, SB 1169, SB 2004, SB 2253, SB 2268, SB 2314, SB 2351, SB 2371, SB 2623, SB 2722, SB 2779, SB 2920, HJR 4, SB 407, SB 1395, SB 1433, SB 1718, SB 2322, SB 2877, SB 619, SB 646, SB 1026, SB 2742, SB 2880, SR 443, SR 449, SR 456, SR 460, SR 465, SCR 46, SB 260, SB 3062, HJR 8, HJR 31, HJR 72, HJR 99, HJR 133, HB 29, HB 33, HB 50, HB 107, HB 116, HB 125, HB 140, HB 141, HB 155, HB 171, HB 227, HB 255, HB 363, HB 368, HB 491, HB 609, HB 630, HB 745, HB 767, HB 913, HB 917, HB 1135, HB 1188, HB 1238, HB 1242, HB 1261, HB 1318, HB 1404, HB 1495, HB 1507, HB 1606, HB 1708, HB 1748, HB 1851, HB 1922, HB 2002, HB 2003, HB 2198, HB 2355, HB 2358, HB 2415, HB 2457, HB 2495, HB 2546, HB 2637, HB 2763, HB 2765, HB 2798, HB 2818, HB 3228, HB 3307, HB 4116, HCR 29, SB 1410, SB 3062, HJR 8, HJR 31, HJR 72, HJR 99, HJR 133, HB 29, HB 33, HB 50, HB 107, HB 116, HB 125, HB 140, HB 141, HB 155, HB 171, HB 227, HB 255, HB 363, HB 368, HB 491, HB 609, HB 630, HB 745, HB 767, HB 913, HB 917, HB 1135, HB 1188, HB 1238, HB 1242, HB 1261, HB 1318, HB 1404, HB 1495, HB 1507, HB 1606, HB 1708, HB 1748, HB 1851, HB 1922, HB 2002, HB 2003, HB 2198, HB 2355, HB 2358, HB 2415, HB 2457, HB 2495, HB 2546, HB 2637, HB 2763, HB 2765, HB 2798, HB 2818, HB 3228, HB 3307, HB 4116, HCR 29, SB 1410

Keywords: education funding, Texas State Technical College System, capital projects, infrastructure, higher education, Birding Capital, Matagorda County, wildlife, conservation, Texas Legislature, Texas beef, cattle industry, agricultural heritage, Texas strip steak, economic growth, SB 31, Life of the Mother Act, Texas abortion law, medical emergency, reasonable medical judgment

Transcript Highlights:

• Greg Abbott, Governor of the State of Texas, by the authority vested in me by Article 3, Sections 5, 5a

Keywords: 997, house, all

Transcript Highlights:

• we're going to actually use adult students and any students that are in the Workforce Development classes
• It was actually very good for a small community college because the classes were small.
• And I'm not talking about the 5A schools. I'm talking about the 1A going on up from there.

Bills: SB194, SB200, SB203, SB204, SJR3

Keywords: appropriation, higher education, sports facilities, community college, Luna Community College, KANW, educational radio, rural news, public education, funding, education, documentary, historical figure, Padre Antonio Jose Martinez, cultural heritage, research funding, federal funding, New Mexico, University of New Mexico, New Mexico State University

Transcript Highlights:

• Members, this is Senate Bill 375 by Senator Mizell relative to firefighting foam, to provide for Class
• Amendment number four would amend subsections B and C of R.S. 40:1615 to provide that Class B firefighting

Bills: HB744, HR197, SB54, SB79, SB163, SB287, SB375, SB386, SB398, SB469, SCR5

Keywords: public utility, common carrier, regulation, Public Service Commission, New Orleans, constitutional amendment, distributed energy, energy storage, electricity demand, virtual power plants, reliability, hurricane resilience, esthetics, cosmetology, hair services, beauty industry, Louisiana regulation, Louisiana Economic Development, sunset law, legislative authority

Summary: The House Committee on Commerce met on May 11, 2026, and first advanced several Senate measures with little or no opposition. It reported favorably Senate Bill 79 recreating Louisiana Economic Development, Senate Concurrent Resolution 5 establishing the Louisiana-Ireland Trade Commission, and Senate Bill 375 on Class B firefighting foam, after adopting a technical amendment clarifying use in declared emergency firefighting operations. The committee also advanced Senate Bill 398, which moves manufactured and modular housing regulation under the Louisiana Contractors Licensing Board and expands inspection and enforcement provisions, after adopting two sets of mostly technical amendments and hearing testimony that the change would improve consumer safety and increase inspection coverage without adding net cost to locals. It then reported favorably Senate Bill 163 on virtual currency business licensing, after adopting an amendment providing that any future federal licensing law would preempt the state act, and Senate Bill 287 on virtual currency kiosks, which adds refund timelines, disclosure requirements, customer support, and reporting duties; witnesses from the banking and law enforcement community said the bill responds to common fraud complaints and improves consumer protection. The committee also reported favorably Senate Bill 54, which allows estheticians to blow-dry hair after certain services, despite strong opposition from cosmetology board representatives and industry witnesses who argued the service is outside esthetics training, could create scope-of-practice and facility issues, and should instead be addressed by lowering or revising separate blow-dry licensing requirements. The committee then considered House Resolution 197, which urges the Louisiana Public Service Commission to study the feasibility and value of distributed energy generation and storage resources. After adopting technical amendments and a second amendment changing mandatory language to requests and urging the PSC to coordinate with the LSU Energy Institute, the resolution was reported favorably. Testimony from solar and energy industry representatives, the PSC, and LSU focused on how distributed resources, batteries, rooftop solar, and virtual power plants could improve reliability, reduce costs, and help meet rising demand; members also discussed how the study would evaluate market value, avoided costs, and capacity benefits. Questions centered on methodology, grid impacts, and comparisons to Texas’s ERCOT system and Winter Storm Uri, with PSC officials emphasizing that the study would help determine whether such resources benefit ratepayers. Representative Wright presented House Bill 744, a proposed constitutional amendment to transfer regulation of certain New Orleans utilities from the city council to the Public Service Commission. He argued the change could reduce rates through consolidation and eliminate duplicative regulatory costs, while PSC officials explained the city’s authority is a constitutional exception dating back to 1921 and that Entergy New Orleans and Entergy Louisiana operate as separate companies with different regulatory environments. After discussion of rate impacts, utility structure, and whether the proposal should instead become a study, the bill was deferred. The committee then began Senate Bill 386, the Louisiana Data Privacy Act, which would give consumers rights to access, correct, delete, and opt out of certain uses of personal data; the sponsor introduced the bill and the committee started considering technical and substantive amendments, but the transcript ends before final action on that measure.

Bills: HB202, HB42, HB146, HB492, HB285, HB7, HB454, HB42, HB7

Keywords: law enforcement, immunity, civil liability, use of force, recruitment, bail reform, cash deposit, judicial discretion, criminal justice, Alabama law, youthful offender, capital murder, public safety, victims' rights, juvenile offenders, delinquent acts, juvenile court, nonfelony offenses, water safety offenses, HB285

Bills: SB243, SB1586, SB1891, SB1959, SB2159, SB2568

Keywords: migrant labor housing, migrant housing, farmworker housing, migrant agricultural worker, agricultural labor, farm labor contractor, Texas Department of Housing and Community Affairs, TDHCA, civil penalty, housing code enforcement, sanitation, occupancy standards, retaliation, worker complaint, language access, Spanish-language outreach, H-2A visa, temporary agricultural workers, unlicensed housing, rural housing

Bills: SB1224, SB2972, SB2615, SB735, SB800, SB2986, SB2310, SB2055, SB1049, SB784

Keywords: educator misconduct, reporting requirements, local law enforcement, public and private schools, penalties for non-compliance, expressive activities, freedom of speech, public forum, higher education, protests, student rights, telework, public education, employee rights, emergency provisions, Holocaust education, Holocaust Remembrance Week, antisemitism, genocide education, public schools

Transcript Highlights:

• nation, the DT Global Laboratory for Energy Asset Management, called GLEAM, is a one-of-a-kind megawatt-class

Bills: SB75, SB715, SB776, SB1299, SB1405, SB1968, SB2021, SB2077, SB2148, SB2321, SB2330, SB2411

Keywords: electric generation, reliability, ERCOT, Public Utility Commission, penalties, performance requirements, energy policy, construction contracts, compensatory damages, government delays, contractor, legislation, nonprofit donor privacy, membership lists, supporter confidentiality, volunteer privacy, association rights, public records exemption, Texas Public Information Act, government transparency

Transcript Highlights:

• can do it through an ADER, and if that's what's holding back the industry, I think we need to have a class-in-five
• It seems to create protected classes with different rights to assembly and speech, possibly violating

Bills: SB75, SB715, SB776, SB1299, SB1405, SB1968, SB2021, SB2077, SB2148, SB2321, SB2330, SB2411

Keywords: electric generation, reliability, ERCOT, Public Utility Commission, penalties, performance requirements, energy policy, construction contracts, compensatory damages, government delays, contractor, legislation, nonprofit donor privacy, membership lists, supporter confidentiality, volunteer privacy, association rights, public records exemption, Texas Public Information Act, government transparency

Transcript Highlights:

• And if that's what's holding back the industry, I think we need to have a class in filling out forms,
• The fact that there's a carve-out or exception for certain professions seems to create protected classes

Bills: SB75, SB715, SB776, SB1299, SB1405, SB1968, SB2021, SB2077, SB2148, SB2321, SB2330, SB2411

Keywords: electric generation, reliability, ERCOT, Public Utility Commission, penalties, performance requirements, energy policy, construction contracts, compensatory damages, government delays, contractor, legislation, nonprofit donor privacy, membership lists, supporter confidentiality, volunteer privacy, association rights, public records exemption, Texas Public Information Act, government transparency

Summary: The Senate Committee on Business and Commerce heard Senate Bill 2021 by Senator Johnson, as substituted, on distributed energy resources (DERs). Johnson said the bill was intended to create a regulatory framework for DERs and virtual power plants, address interconnection and registration issues, and prevent regulatory capture as the industry grows. Testimony was split: Texas Electric Cooperatives asked for clarification so co-ops would not be unintentionally excluded from owning or operating DERs; AECT supported the bill as providing needed rules and customer protections; TABA, Texas Solar and Storage Association, Sierra Club, Texas Solar Energy Society, and several others opposed it or raised concerns that it was too utility-centric, imposed red tape, and could burden homeowners and small businesses with registration and interconnection requirements. Johnson repeatedly said the bill was not meant to stop rooftop solar or backup systems and that he was open to specific redlines and further changes. SB 2021 was left pending after testimony. The committee then took up Senate Bill 2330 by Senator Parker, which would end government payroll deduction for dues to certain public employee organizations, while exempting first responders under Chapters 143 and 147 and making other conforming changes in a committee substitute. Parker argued the bill was about government neutrality, transparency, and employee freedom from coercion, and said organizations can collect dues directly using modern payment methods. Supporters from Texas Public Policy Foundation, Texas Business Coalition, Freedom Foundation, ABC Texas, and Texans for Fiscal Responsibility said taxpayer-funded payroll systems should not be used to collect dues for private organizations, especially ones involved in political activity. Opponents, including ATPE, Texas Classroom Teachers Association, Texas Public Employees Association, and correctional employees, said payroll deduction is a convenient, secure service that helps professional associations and employee groups, and argued the bill would burden teachers and other public employees. Several witnesses and senators focused on the bill’s exemptions and whether it treated teachers differently from first responders. Senator Menendez questioned why some public employees were excluded while others were not, and a Houston police union representative said he moved from opposing to supporting the bill after being told the substitute would preserve meet-and-confer deductions under Chapters 143 and 147. Senator Parker closed by saying the bill was not meant to eliminate associations or payroll deduction entirely, only to remove the state as a middleman. SB 2330 was left pending, and the committee then recessed subject to call.

Transcript Highlights:

• The TTU Global Laboratory for Energy Asset Management, called GLEAM, is a one-of-a-kind megawatt-class

Bills: SB75, SB715, SB776, SB1299, SB1405, SB1968, SB2021, SB2077, SB2148, SB2321, SB2330, SB2411

Keywords: electric generation, reliability, ERCOT, Public Utility Commission, penalties, performance requirements, energy policy, construction contracts, compensatory damages, government delays, contractor, legislation, nonprofit donor privacy, membership lists, supporter confidentiality, volunteer privacy, association rights, public records exemption, Texas Public Information Act, government transparency

Summary: The committee first took up pending business and favorably reported several bills without objection or by recorded vote, including SB 783, SB 1238, SB 1706, SB 1791, SB 458, SB 1644, and SB 1810, with some of them also sent to the local and uncontested calendar. The committee then moved into hearings on additional bills. SB 1968, by Senator Schwertner, would update the Real Estate License Act by repealing subagency, requiring written buyer-agent agreements before showings, and clarifying when a formal buyer representation agreement must be signed. Texas Realtors testified in support, saying the bill modernizes agency rules and increases transparency, while a committee substitute corrected drafting issues. SB 2411, the annual update to the Texas Business Organizations Code, was also laid out and left pending after supportive testimony from the Texas Business Law Foundation and drafting committee representatives. The committee also heard SB 2321, which would codify ERCOT’s current practice of notifying TCEQ when backup generation needs enforcement discretion for grid reliability; Sierra Club and a chamber of commerce witness supported it with suggestions for clearer emissions reporting, and the bill was left pending. SB 2077 would broaden eligibility for the Texas Mutual Insurance Company board by narrowing conflict restrictions tied to insurance-related interests; Texas Mutual supported the change and the bill was left pending. SB 1405, a broadband bill, would align state law with FCC standards and streamline Broadband Development Office processes; it was left pending after supportive testimony. SB 1299, protecting nonprofit donor privacy, drew support from privacy advocates and concerns from one witness about transparency for publicly funded nonprofit operations; it was left pending. The committee then heard SB 776, which would bar government construction contracts from shifting delay damages to contractors when delays are caused solely by the public owner. Contractors, surety representatives, and water infrastructure advocates supported the bill, arguing it would improve fairness and reduce inflated bids, while water utilities and critical infrastructure entities opposed it, warning of more litigation and higher costs; the bill was left pending. Finally, SB 715, which would apply reliability requirements retroactively to all generation resources in ERCOT, drew opposition from renewable and storage groups and support from some critics of renewable subsidies, with witnesses split over whether it would improve reliability or raise costs; testimony was underway when the transcript ended.

Transcript Highlights:

• Uh, paragraph five of the amended 5A, no metered parking fee shall be charged at any state park lot,
• Uh, paragraph five of the amended 5A,<00:08:15.360> no<00:08:15.520> metered<00:08:15.919
• > parking<00:08:16.240> fee<00:08:16.479> shall<00:08:16.720> be 5A, no metered
• parking fee shall be 5A, no metered parking fee shall be charged<00:08:17.039> at<00:08:17.280

Keywords: 1191, senate, all

Transcript Highlights:

• Item 5A this morning in your books is an update to the PSFA's project status report managed by our agency's