Transcript Highlights:

• Our district is committed to providing high-quality education that prepares our students for success,
• Our facilities are aging, space is limited, and they no longer meet the needs of our students, staff,
• We can reinvest that money directly into our students, into safer buildings, better classrooms, more
• Student loans were added to that exclusion and were considered payments on employees' student loans.
• Student loans were added to the definition of educational assistance payments.

Bills: HF1833, HF148, HF1127, HF1227, HF1681, HF1974, HF1106, HF1016, HF2197

Keywords: sales tax, education funding, construction, Aitkin Public Schools, tax exemption, refundable credit, HF148, use of force training, deadly force, peace officer training, police training, law enforcement, POST Board, Board of Peace Officer Standards and Training, scenario-based training, de-escalation, defensive tactics, force-on-force training, stress management, officer wellness

Transcript Highlights:

• There are a number of pieces to this bill that sort of span from updating student loan borrower bills

Bills: HF1546, HF2403, HF2389, HF2398

Keywords: fire safety, public safety, statewide fire code, code cleanup, repeal, obsolete statutes, matches, strike-anywhere matches, safety matches, match packaging, match storage, tent safety, flame resistant tents, public assembly tents, flammable materials, fire code modernization, Minnesota Statutes chapter 325F, commerce policy, financial institutions, insurance regulation

Transcript Highlights:

• Chairman. 3037 amends the Government Tort Claims Act by adding students engaged in curricular activities

Bills: HB1016, HB1453, HB1992, HB2015, HB2940, HB2959, HB2997, HB3037, HB3045, HB3053, HB3087, HB3267, HB3301, HB3453, HB3495, HB3521, HB3581, HB3584, HB3586, HB3587, HB3662, HB3691, HB3695, HB3697, HB3742, HB3743, HB3845, HB4058, HB4125, HB4198, HB4227, HB4425

Keywords: minors, content creation, trust account, compensation, civil action, digital content, Oklahoma statutes, foreign ownership, property rights, agricultural land, Attorney General, divestment, real estate, felony penalties, motor vehicles, towing services, combination vehicles, wrecker fees, possessory lien, landlord

Bills: SB 2, SB 5, SB 10, SB 9, SB 7, SB 17, SB 4, HB17, HB7, HB7, HB15, HB15, HB27, HB1, HB7, HB15, HB18, SB9, SB7, SB17, SB4, HB17, HB27, HB1, SB8, HCR13, SB2, SB5, SB10

Keywords: disaster relief, flood preparedness, emergency funding, local government support, meteorological forecasting, school assessment, public education, accountability, transparency, education standards, STAAR, Texas Education Agency, TEA, public school accountability, school ratings, A-F ratings, assessment reform, student testing, benchmark tests, interim assessments

Bills: SB 2, SB 5, SB 10, SB 9, SB 7, SB 17, SB 4, HB17, HB7, HB7, HB15, HB15, HB27, HB1, HB7, HB15, HB18, SB9, SB7, SB17, SB4, HB17, HB27, HB1, SB8, HCR13, SB2, SB5, SB10

Keywords: disaster relief, flood preparedness, emergency funding, local government support, meteorological forecasting, school assessment, public education, accountability, transparency, education standards, STAAR, Texas Education Agency, TEA, public school accountability, school ratings, A-F ratings, assessment reform, student testing, benchmark tests, interim assessments

Bills: SB 2, SB 5, SB 10, SB 9, SB 7, SB 17, SB 4, HB17, HB7, HB7, HB15, HB15, HB27, HB1, HB7, HB15, HB18, SB9, SB7, SB17, SB4, HB17, HB27, HB1, SB8, HCR13, SB2, SB5, SB10

Keywords: disaster relief, flood preparedness, emergency funding, local government support, meteorological forecasting, school assessment, public education, accountability, transparency, education standards, STAAR, Texas Education Agency, TEA, public school accountability, school ratings, A-F ratings, assessment reform, student testing, benchmark tests, interim assessments

Transcript Highlights:

• University System is a three billion dollar enterprise with over 64,000 students and more than 21,000
• It has over 40,000 students and nearly two decades of record-breaking enrollment.
• I'm honored to join Senator Perry. just in commending the Texas Tech. 125 students, and for the great
• The influence of South Texas ISD reaches well beyond the accomplishments of its students.
• Specifically, the per-student allotment would increase from $10 for each student in average daily attendance

Bills: SJR18, SCR9, SCR13, SB10, SB11, SB19, SB20, SB25, SB62, SB260, SB263, SB293, SB314, SB384, SB412, SB441, SB442, SB494, SB523, SB569, SB616, SB688, SB707, SB766, SB842, SB869, SB890, SB914, SB929, SB971, SB992, SB1066, SB1145, SB1621, SJR36, SJR18, SCR9, SCR13, SB616, SB565, SB384, SB372, SB495, SB842, SB971, SB1066, SB929, SB765, SB523, SB62, SB19, SB18, SB666, SB688, SB707, SB888, SB687, SB706, SB847, SB869, SB890, SB992, SB1145, SB494, SB290, SB766, SB11, SB10, SB13, SB263, SB412, SB20, SB441, SB442, SB1621, SB569, SB314, SB25, SB293, SB914, SB260, SB1248, SB740, SB14, SB1006, SB20, SB25, SB260, SB293, SB314, SB384, SB442, SB494, SB616, SB869, SB890, SB929, SB992, SB1145, SB1621, SR232, SR237, SR242, SB16, SB22

Keywords: capital gains, taxation, constitutional amendment, state revenue, individual investment, Supreme Court, judicial independence, Keep Nine, checks and balances, water rights, treaty compliance, Rio Grande, agriculture, drought, international water, Texas water supply, education, Ten Commandments, public schools, religious display

Transcript Highlights:

• WE HAVE STUDENTS VISITING FROM LAKELAND CHRISTIAN SCHOOL.
• IN 2018, WE HAD ONE IN 44 STUDENTS. DIAGNOSED WITH AUTISM.
• We know what the learning loss is for regular students in regular schools.
• I have a couple of students visiting from the College of Florida Keys in the West Gallery: Joshua and
• They are students within the Project Access program who are students with autism and are learning life

Bills: SJR18, SCR9, SCR13, SB10, SB11, SB19, SB20, SB25, SB62, SB260, SB263, SB293, SB314, SB384, SB412, SB441, SB442, SB494, SB523, SB569, SB616, SB688, SB707, SB766, SB842, SB869, SB890, SB914, SB929, SB971, SB992, SB1066, SB1145, SB1621, SJR36, SJR18, SCR9, SCR13, SB616, SB565, SB384, SB372, SB495, SB842, SB971, SB1066, SB929, SB765, SB523, SB62, SB19, SB18, SB666, SB688, SB707, SB888, SB687, SB706, SB847, SB869, SB890, SB992, SB1145, SB494, SB290, SB766, SB11, SB10, SB13, SB263, SB412, SB20, SB441, SB442, SB1621, SB569, SB314, SB25, SB293, SB914, SB260, SB1248, SB740, SB14, SB1006, SB20, SB25, SB260, SB293, SB314, SB384, SB442, SB494, SB616, SB869, SB890, SB929, SB992, SB1145, SB1621, SR232, SR237, SR242, SB16, SB22

Keywords: capital gains, taxation, constitutional amendment, state revenue, individual investment, Supreme Court, judicial independence, Keep Nine, checks and balances, water rights, treaty compliance, Rio Grande, agriculture, drought, international water, Texas water supply, education, Ten Commandments, public schools, religious display

Transcript Highlights:

• She is here today for her annual day on the hill with her undergraduate students who are all studying
• And I just want to thank you for leading our students with wisdom, your wisdom, and integrity.

Bills: SB1636, SB1584, SB1730, SB1255, SB1627, SB137, SB2062, SB1470, SB1284, SB1632, SB1594, SB2045, SB1251, SB1884, SB1250, SB1630, SB1262, SB1374, SB1292, SB1432, SB1199, SB1790, SB1481, SB1614, SB1734, SB1437, SB1489, SB1718, SB1778, SB1327, SB1372, SB1403, SB1937, SB277, SB2131, SB1749, SB1348, SB1469, SB2018, SB1931, SB1530, SB2155, SB2030, SB1926, SB2170, SB2151, SB2166, SB1213, SB1381, SB1824, SB1876, SB1728, SB1582, SB1286, SB1386, SB1708, SB1618, SB2106, SB1471, SB2139, SB2154, SB1619, SCR15, HB2786, HB2787, SB1525, SB2011, SB2159

Keywords: cold case, unsolved homicide, violent crime, case file review, law enforcement, police records, victim family, immediate family member, designated person, forensic testing, witness reinterview, investigative leads, cold case unit, unsolved murder, public safety, Title 21, Oklahoma statutes, sexual assault, evidence kits, DNA testing

Transcript Highlights:

• Is this the example that we want to set for our students?
• Do we allow students to boo their classmates when they disagree or use intimidation and moblike tactics
• Our students deserve better, Mr. President.
• Our students deserve better, structure. Our students deserve better, Mr.<00:07:29.199> President.

Bills: SB2347, SB2911, SB2033, SB2158, SB2993, SB2778, SB2672, SB2014, SB3144, SB3096, SB3097, SB2968, SB2363, SB3154, SB2400, SB3313, SB2896, SB3279, SB2614, SB2687, SB2754, SB2549, SB3325, SB2658, SB2659, SB2602, SB2611, SB2877, SB3063, SB2615, SB3232, SB2875, SB3272, SB2854, SB3203, SB2803, SB2804, SB3302, SB3229, SB2969, SB2412, SB2657, SB2880, SB2540, SB2414, SB3142, SB3202, SB2281, SB2852, SB2272, SB2479, SB2589, SB2936, SB2720, SB2730, SB2749, SB2688, SB2798, SB3040, SB3107, SB3010, SB3109, SB3140, SB3187, SB2057, SB2377, SB3048, SB3083, SB3182

Keywords: tenant rights, landlord obligations, housing crisis, eviction prevention, multilingual access, intoxicating liquor, direct shipment, breweries, distilleries, Hawaii, renewable energy, grid-ready homes, interconnection process, electric utility, energy independence, surcharge, customer access, energy storage, smart inverters, veterinary workforce

Transcript Highlights:

• health of our students. of our great state.
• I'm the mom of two public school students.
• No way for students to get to class.
• Because my mother told me, you are a 100 A student, you are not a 97 A student.
• HB 213 by Gonzales of El Paso relating to the inclusion of chronically absent students as students at

Bills: HB630, HB420, HB767, HB1708, HB2842, HB1404, HB2457, HB140, HB333, HB227, HB913, HB201, HB2198, HB 109, HB2763, HB519, HB 1261, HB 1135, HB1318, HB2358, HB2415, HB2765, HB2735, HB3307, HB1373, HB694, HB 1242, HB272, HB1437, HB1888, HCR78, HCR12, HCR128, HR7, HR11, HR37, HR69, HR83, HR89, HR100, HR123, HR129, HR137, HR254, HR258, HR289, HR293, HR318, HR324, HR350, HR368, HR370, HR372, HR379, HR406, HR407, HR432, HR445, HR471, HR504, HR506, HR507, HR528, HR567, HR572, HR591, HR592, HR593, HR603, HR614, HR621, HR673, HR684, HR685, HR687, HR700, HR701, HR711, HR712, HR754, HR757, HR758, HR760, HR764, HR765, HR766, HR767, HR768, HR769, HR770, HR771, HR772, HR774, HR776, HR777, HR778, HR779, HR780, HR783, HR784, HR784, HR6, HR6, HR17, HR17, HR18, HR18, HR49, HR49, HR170, HR170, HR236, HR236, HR247, HR275, HR355, HR356, HR364, HR672, HR690, HR690, HR755, HR755, HR756, HR756, HR759, HR759, HR762, HR762, HR763, HR763, HR781, HR781, HR785, HR785, SB2, SB260, SB569, HB2, HB2000, HB213, HB222, HB645, HB1458, HB 1022, HB141, HB643, HB3093, HB1700, HB 117

Keywords: outboard motors, certificate of title, vessel regulation, Texas Parks and Wildlife Code, marine documentation, HB 420, Texas Water Code, special district, water district, board meetings, meeting location, teleconference, videoconference, remote meeting, public hearing, tax rate hearing, special districts, Cedar Creek Reservoir, county boundary, local government

Transcript Highlights:

• a vested interest in the financial health and long-term success of the economy, the contractors performing
• for delay clauses, creates unacceptable levels of risk that can threaten a contractor's ability to perform

Bills: SB75, SB715, SB776, SB1299, SB1405, SB1968, SB2021, SB2077, SB2148, SB2321, SB2330, SB2411

Keywords: electric generation, reliability, ERCOT, Public Utility Commission, penalties, performance requirements, energy policy, construction contracts, compensatory damages, government delays, contractor, legislation, nonprofit donor privacy, membership lists, supporter confidentiality, volunteer privacy, association rights, public records exemption, Texas Public Information Act, government transparency

Transcript Highlights:

• Texas has nearly 700,000 public school employees who serve 5.5 million students every day.
• My organization has empowered me to speak up for the rights of employees. of students with disabilities
• It has been an important bridge between the district administration, employees, students, and parents
• retain public school employees and allows them to communicate their needs and the needs of their students
• I can't wait to tell my students about it. Thank you.

Bills: SB75, SB715, SB776, SB1299, SB1405, SB1968, SB2021, SB2077, SB2148, SB2321, SB2330, SB2411

Keywords: electric generation, reliability, ERCOT, Public Utility Commission, penalties, performance requirements, energy policy, construction contracts, compensatory damages, government delays, contractor, legislation, nonprofit donor privacy, membership lists, supporter confidentiality, volunteer privacy, association rights, public records exemption, Texas Public Information Act, government transparency

Transcript Highlights:

• Texas has nearly 700,000 public school employees who serve 5.5 million students every day.
• My organization has empowered me to speak up for the rights of students with disabilities.
• It has been an important bridge between the district administration, employees, students, and parents
• I can't wait to tell my students about it. Thank you.
• With that, we're going to close up for testimony and leave. ...to tell my students about it.

Bills: SB75, SB715, SB776, SB1299, SB1405, SB1968, SB2021, SB2077, SB2148, SB2321, SB2330, SB2411

Keywords: electric generation, reliability, ERCOT, Public Utility Commission, penalties, performance requirements, energy policy, construction contracts, compensatory damages, government delays, contractor, legislation, nonprofit donor privacy, membership lists, supporter confidentiality, volunteer privacy, association rights, public records exemption, Texas Public Information Act, government transparency

Summary: The Senate Committee on Business and Commerce heard Senate Bill 2021 by Senator Johnson, as substituted, on distributed energy resources (DERs). Johnson said the bill was intended to create a regulatory framework for DERs and virtual power plants, address interconnection and registration issues, and prevent regulatory capture as the industry grows. Testimony was split: Texas Electric Cooperatives asked for clarification so co-ops would not be unintentionally excluded from owning or operating DERs; AECT supported the bill as providing needed rules and customer protections; TABA, Texas Solar and Storage Association, Sierra Club, Texas Solar Energy Society, and several others opposed it or raised concerns that it was too utility-centric, imposed red tape, and could burden homeowners and small businesses with registration and interconnection requirements. Johnson repeatedly said the bill was not meant to stop rooftop solar or backup systems and that he was open to specific redlines and further changes. SB 2021 was left pending after testimony. The committee then took up Senate Bill 2330 by Senator Parker, which would end government payroll deduction for dues to certain public employee organizations, while exempting first responders under Chapters 143 and 147 and making other conforming changes in a committee substitute. Parker argued the bill was about government neutrality, transparency, and employee freedom from coercion, and said organizations can collect dues directly using modern payment methods. Supporters from Texas Public Policy Foundation, Texas Business Coalition, Freedom Foundation, ABC Texas, and Texans for Fiscal Responsibility said taxpayer-funded payroll systems should not be used to collect dues for private organizations, especially ones involved in political activity. Opponents, including ATPE, Texas Classroom Teachers Association, Texas Public Employees Association, and correctional employees, said payroll deduction is a convenient, secure service that helps professional associations and employee groups, and argued the bill would burden teachers and other public employees. Several witnesses and senators focused on the bill’s exemptions and whether it treated teachers differently from first responders. Senator Menendez questioned why some public employees were excluded while others were not, and a Houston police union representative said he moved from opposing to supporting the bill after being told the substitute would preserve meet-and-confer deductions under Chapters 143 and 147. Senator Parker closed by saying the bill was not meant to eliminate associations or payroll deduction entirely, only to remove the state as a middleman. SB 2330 was left pending, and the committee then recessed subject to call.

Transcript Highlights:

• companies have a vested interest in the financial health and long-term success of the contractors performing
• no-damage-for-delay clauses, it creates unacceptable levels of risk that can threaten a contractor's ability to perform
• companies have a vested interest in their financial health and long-term success of the contractors performing
• When public contracts contain provisions that eliminate, performing for work and they back.
• delay clauses, it creates unacceptable levels of risk that can threaten a contractor's ability to perform

Bills: SB75, SB715, SB776, SB1299, SB1405, SB1968, SB2021, SB2077, SB2148, SB2321, SB2330, SB2411

Keywords: electric generation, reliability, ERCOT, Public Utility Commission, penalties, performance requirements, energy policy, construction contracts, compensatory damages, government delays, contractor, legislation, nonprofit donor privacy, membership lists, supporter confidentiality, volunteer privacy, association rights, public records exemption, Texas Public Information Act, government transparency

Summary: The committee first took up pending business and favorably reported several bills without objection or by recorded vote, including SB 783, SB 1238, SB 1706, SB 1791, SB 458, SB 1644, and SB 1810, with some of them also sent to the local and uncontested calendar. The committee then moved into hearings on additional bills. SB 1968, by Senator Schwertner, would update the Real Estate License Act by repealing subagency, requiring written buyer-agent agreements before showings, and clarifying when a formal buyer representation agreement must be signed. Texas Realtors testified in support, saying the bill modernizes agency rules and increases transparency, while a committee substitute corrected drafting issues. SB 2411, the annual update to the Texas Business Organizations Code, was also laid out and left pending after supportive testimony from the Texas Business Law Foundation and drafting committee representatives. The committee also heard SB 2321, which would codify ERCOT’s current practice of notifying TCEQ when backup generation needs enforcement discretion for grid reliability; Sierra Club and a chamber of commerce witness supported it with suggestions for clearer emissions reporting, and the bill was left pending. SB 2077 would broaden eligibility for the Texas Mutual Insurance Company board by narrowing conflict restrictions tied to insurance-related interests; Texas Mutual supported the change and the bill was left pending. SB 1405, a broadband bill, would align state law with FCC standards and streamline Broadband Development Office processes; it was left pending after supportive testimony. SB 1299, protecting nonprofit donor privacy, drew support from privacy advocates and concerns from one witness about transparency for publicly funded nonprofit operations; it was left pending. The committee then heard SB 776, which would bar government construction contracts from shifting delay damages to contractors when delays are caused solely by the public owner. Contractors, surety representatives, and water infrastructure advocates supported the bill, arguing it would improve fairness and reduce inflated bids, while water utilities and critical infrastructure entities opposed it, warning of more litigation and higher costs; the bill was left pending. Finally, SB 715, which would apply reliability requirements retroactively to all generation resources in ERCOT, drew opposition from renewable and storage groups and support from some critics of renewable subsidies, with witnesses split over whether it would improve reliability or raise costs; testimony was underway when the transcript ended.

Bills: HB145, HR1, HB80, SB29, SB37, HB206, SB193, SB58, SB64, HB153, HB195, HB234, HB248, HB255, HB279, HB287, HB292, HB303, HB309, HB371, SB30, SB35, SB40, SB43, SB48, SB96, SB143, HJM1, HM7, HM17, HM4, HM22, HM23, HM24, HM26, HM2, HM16, HM32, HM13, HM47, HM20, HM51, HM1, HM31, HM35, HM36, HM46, HM53, HM54, HM39, HM29, HM43, HM59, HM11, HM14, HM21, HM34, HM50

Keywords: high-wage jobs, tax credit, job creation, New Mexico, economic development, House Resolution 1, HR1, House investigatory subcommittee, special committee, legislative investigation, subpoena power, public corruption, criminal activity, Zorro ranch, Santa Fe County, public accountability, government oversight, impeachment power, children and vulnerable persons, public funds

Transcript Highlights:

• Senate Bill 1016 by Blanco relates to student union building fees at the University of Texas at El Paso
• Senate Bill 1066 by Perry relates to requiring payment in performance bonds for certain public work contracts
• Middleton relates to the procedure for resolving allegations of religious discrimination against a student
• Senate Bill 1092 by Zaffirini relates to the referral of certain students receiving special education

Bills: SJR36, SB26, SJR3, SJR48, SJR50, SJR51, SCR15, SCR17, SB3, SB5, SB12, SB18, SB1001, SB1002, SB1003, SB1004, SB1005, SB1006, SB1007, SB1008, SB1009, SB1010, SB1011, SB1012, SB1013, SB1014, SB1015, SB1016, SB1017, SB1018, SB1019, SB1020, SB1021, SB1022, SB1023, SB1024, SB1025, SB1026, SB1027, SB1028, SB1029, SB1030, SB1031, SB1032, SB1033, SB1034, SB1035, SB1036, SB1037, SB1038, SB1039, SB1040, SB1041, SB1042, SB1043, SB1044, SB1045, SB1046, SB1049, SB1050, SB1051, SB1052, SB1053, SB1054, SB1055, SB1056, SB1057, SB1058, SB1059, SB1060, SB1061, SB1062, SB1063, SB1064, SB1065, SB1066, SB1067, SB1068, SB1069, SB1070, SB1071, SB1072, SB1073, SB1074, SB1075, SB1076, SB1077, SB1078, SB1079, SB1080, SB1081, SB1082, SB1083, SB1084, SB1085, SB1086, SB1087, SB1088, SB1089, SB1090, SB1091, SB1092, SB1093, SB1094, SB1095, SB1096, SB1097, SB1098, SB1099, SB1100, SB1101, SB1102, SB1103, SB1104, SB1105, SB1106, SB1107, SB1108, SB1109, SB1110, SB1111, SB1112, SB1113, SB1114, SB1115, SB1116, SB1117, SB1118, SB1119, SB1120, SB1121, SB1122, SB1123, SB1124, SB1125, SB1126, SB1127, SB1128, SB1129, SB1130, SB1131, SB1132, SB1133, SB1134, SB1135, SB1136, SB1137, SB1138, SB1139, SB1140, SB1141, SB1142, SB1143, SB1144, SB1145, SB1146, SB1147, SB1148, SB1149, SB1150, SB1565

Keywords: teacher compensation, education funding, public school educators, teacher retention, teacher designation, dementia, Alzheimer's disease, Parkinson's disease, research funding, state budget, prevention, healthcare, medical research, Dementia Prevention and Research Institute, severance tax, oil and gas, Texas STRONG fund, economic stabilization, public health, property tax relief

Transcript Highlights:

• They are the student of the Duke University.
• And it performed the way that it performed when you were flying it, when you started flying it. offline
• I want to address our students here.
• I'm just here as a student. I'm an iPhone student. I'm an internet student. I study.
• I say identity as the internal student, as the F1 student.

Bills: HB17, HB34, HB41, HB 118, HB 119, HB 127, HB 128, HB 129, HB 130, HB132, HB133, HB17, HB41, HB118, HB119, HB127, HB128, HB129, HB130, HB132, HB133

Keywords: foreign ownership, real estate, national security, designated countries, Texas property law, lobbying, foreign adversaries, compensation prohibition, transparency, civil penalties, higher education, foreign adversary, research security, trade secrets, academic partnerships, HB 128, sister city, sister-city agreement, international exchange, municipal diplomacy

Transcript Highlights:

• Senator Juarez would like to recognize guests in the North Balcony: students from Creighton University
• Every student deserves access to healthy fish during the day.
• Child nutrition programs see at no cost such student.
• , and student participation.
• 2031-32, and students complete the federal purpose of the last year on December 1, 2032.

Bills: LB764, LB815A, LB839, LB888, LB955, LB972A, LB1029, LB1087, LB1091, LB1126A, LB1181A, LB1237A, LB1261A, LB304A, LB762, LB889, LB929, LB966, LB1022, LB1187, LR508

Keywords: law enforcement, correctional services, Department of Correctional Services, corrections officers, state prison employees, peace officer, certification, police standards, training academy, Nebraska Commission on Law Enforcement and Criminal Justice, Nebraska Police Standards Advisory Council, criminal justice, correctional staff, conditional officer, law enforcement authority, public safety, LB815A, LB815, appropriation, appropriations bill

Transcript Highlights:

• She balanced the demanding roles of a single parent and a full-time student, pushing through paramedic
• Representative, will this legislation improve test scores for students?
• and things that come with that over the years as I'm working with students with various disabilities
• careful to all the entities that have access to students and to these ideologies that come into the
• Speaker, some troubled students, and I very much love all those students, but I've had chairs thrown

Bills: SB1090, SJR49, SB633, HR1059, SB650, SB2063, SB122, SB1614, SB1884, SJR52, SJR53, HJR1101, SJR50, HB3021, HR1058, SB514, SB382, HB3320, SB740, SB833, SB2143, SB1209, SB244

Keywords: wildlife, conservation, Oklahoma, regulations, permanent rules, Leo's Law, child endangerment, fentanyl testing, drug screening, child welfare, Oklahoma Children's Code, substance abuse, Asian/Pacific American Heritage Month, AAPI, Asian American, Pacific Islander, Oklahoma House resolution, commemorative resolution, heritage month, cultural recognition