Transcript Highlights:

• CR 108 from the Subcommittee on International Relations.
• We heard this bill in the Subcommittee on International Relations by Representative... ...and urging
• The US shrimp farms have to adhere to very strict rules and regulations in producing their product.
• Strict rules and guidelines that they have to adhere to.
• The rule and the measure of whether a restaurant is falsely marketing imported shrimp as domestic will

Bills: HB1958, HB2031, HB2879, HB3285, HB3995, HB4487, HB4558, HB4560, HB4876, HB4899, HB5212, HB5317, HB5543, HB5567, SB1333

Keywords: firearm possession, tenant rights, landlord regulations, civil penalties, property code, justified use of force, deadly force, property rights, home defense, smart devices, data privacy, personal data collection, user consent, mobile application, data transparency, HOA, property owners association, property owners' association, Texas Property Code, Chapter 202

Transcript Highlights:

• Inspections at least once every five years as long as this follows federal rules including the Americans
• Senator Zaffirini and recognize the sponsor speaker feeling to explain the bill. the Board of Boiler Rules
• I move that the executive director, who is serving on the board, corrects the voting majority rule by
• Currently the definition of mold under TDLR rules incorrectly includes mycotoxin. substances produced

Bills: HB2450, SB378, SB764, SB917, SB1254, SB1255

Keywords: elevator inspection, building safety, construction standards, health and safety code, regulatory requirements, SB 378, Texas Occupations Code, barbering, cosmetology, barber, cosmetologist, licensing, professional licensing, unauthorized practice, medical procedures, skin incision, dermis, injections, devices, consumer safety

Transcript Highlights:

• on this water and not just look for the industry that's coming in to buy the water to dictate the rules
• Because what happened To dictate the rules of the game, because what happens is the citizens end up paying

Bills: HB16, HB16, HB1618, HB2692, HB2712, HB2970, HB3609, HB3628

Keywords: judicial administration, court reform, juvenile diversion, court security, mental health services, drug offenses, constitutional amendments, water infrastructure, Texas Water Development Board, financial assistance, water supply projects, rural municipalities, water access assessment, aquifer storage, Edwards Aquifer, water injection, environmental regulations, groundwater management, San Antonio River, pollution control

Transcript Highlights:

• current law, all state agencies... ...including TWDB, are required to review their administrative rules
• This creates a disconnect between the rule review cycle and the agency's five-year planning timeline.
• As a result, TWA... ...WDB is forced to review and potentially revise key planning rules out of sync
• provides a straightforward solution: amend the water code to exempt TWDB's water and flooding planning rules
• By aligning the rules and review processes with planning cycles, we can promote consistency, free up

Bills: HB16, HB1618, HB2692, HB2712, HB2970, HB3609, HB3628, HB16

Keywords: water infrastructure, Texas Water Development Board, financial assistance, water supply projects, rural municipalities, water access assessment, aquifer storage, Edwards Aquifer, water injection, environmental regulations, groundwater management, San Antonio River, pollution control, flood management, water quality, conservation district, bonds, utility rates, ratemaking, water services

Transcript Highlights:

• Under the new requirement, the rule of 80 no longer applied, and all members of the tier were required
• They may adopt rules needed to administer and enforce the provisions of the bill effectively.

Bills: HB104, HB2434, HB2529, HB2688, HB3161, HB3486, HB3487, HB3745, HB4044, HB4226, HB4945, HB104

Keywords: Texas Future Fund, investment review board, economic stabilization, innovative technology, national defense, retirement, service credit, Employees Retirement System of Texas, employee benefits, pension reform, salary supplement, county judges, judicial functions, state law, government compensation, public retirement systems, municipality pensions, firefighters, police officers, retirement age

Transcript Highlights:

• to the committee and our visitors and witnesses today, the House committees are subject to the same rules
• Under House rules, a committee member must first seek to be recognized for any purpose.
• discovered that drugs are still making it in, and in some cases, more drugs than before the... tightened rules
• House Bill 3860 will also allow the commission to adopt. the rules allowing the department to accept
• This bill would require TDCJ to adopt rules related to the program. to the leave pool.

Bills: HB153, HB1828, HB2306, HB2498, HB3464, HB3488, HB3636, HB3673, HB3834, HB3860, HB4120, HB4937, HB1515, HB153

Keywords: education, funding, student resources, technology access, equal opportunity, veterans treatment court, mental health, criminal justice, rehabilitation, eligibility criteria, veterans, treatment court, military service, legislation, legislative leave, correctional officers, Texas Department of Criminal Justice, accumulated leave, compensatory time, parole eligibility

Transcript Highlights:

• And there are rules that are in force, but other examples might be imagined, just the adequacy of one's
• That's the goal for us, just to make sure that those rules are followed for the betterment of patient

Bills: HB139, HB1818, HB1942, HB1959, HB2221, HB2254, HB2563, HB2067, HB2275, HB3211, HB139

Keywords: HB 1818, Texas Insurance Code, Texas Department of Insurance, commissioner of insurance, health maintenance organization, HMO, insurer, utilization review, preauthorization, prior authorization, medical necessity review, health care services, medical care, insurance regulation, insurance examination, regulatory oversight, confidential records, public information exception, Chapter 843, Chapter 1301

Transcript Highlights:

• It has binding legal effect, and the rules of procedure and evidence may not be applied strictly.
• born; we said, "Well, what we'll do when we have an entity... ...or a product that involves an international
• Texas has a model that's very comprehensive for international arbitration.
• The International Arbitration Act is more comprehensive than the Federal Arbitration Act, and so these
• So, and I'm sure there's some exceptions to those rules.

Bills: HB139, HB1818, HB1942, HB1959, HB2221, HB2254, HB2563, HB2067, HB2275, HB3211, HB139

Keywords: HB 1818, Texas Insurance Code, Texas Department of Insurance, commissioner of insurance, health maintenance organization, HMO, insurer, utilization review, preauthorization, prior authorization, medical necessity review, health care services, medical care, insurance regulation, insurance examination, regulatory oversight, confidential records, public information exception, Chapter 843, Chapter 1301

Transcript Highlights:

• The commission had written rules that violated 466.
• It codifies the business judgment rule.
• We use the term internal affairs sometimes.
• An internal entity claim. is a claim that concerns the internal affairs of a corporation.
• It's a huge deal. to codify the business judgment rule.

Bills: SB29, SB406, SB447, SB875, SB893, SB1033, SB1346, SB1362, SB1539, SCR22, SB 29

Keywords: business organization, internal management, corporate governance, partnerships, liability reduction, birth certificate, biological sex, gender identity, health and safety, sex assignment, SB 875, Texas, independent school district, ISD, school board trustee, superintendent, campus administrator, electioneering, political signs, early voting

Transcript Highlights:

• SCOTUS has upheld on multiple rulings that the privacy right of donors to nonprofit causes.
• So there's an internal appeal process within the department for all the contractors.
• In 2003, they adopted rules and were never able to fully implement those rules.
• Chairman, because of Texas regulatory rules.
• We do not have rules in place that deal with electromagnetic pulses. We do do planning...

Bills: SB75, SB715, SB776, SB1299, SB1405, SB1968, SB2021, SB2077, SB2148, SB2321, SB2330, SB2411

Keywords: electric generation, reliability, ERCOT, Public Utility Commission, penalties, performance requirements, energy policy, construction contracts, compensatory damages, government delays, contractor, legislation, nonprofit donor privacy, membership lists, supporter confidentiality, volunteer privacy, association rights, public records exemption, Texas Public Information Act, government transparency

Transcript Highlights:

• to do is allow regulatory capture for a couple of big players to come in here and set up a bunch of rules
• On the transmission system, the rules for putting power...
• On the distribution system, the rules need to be clarified, and that's the reason for Senate Bill 2021
• In this bill, the next big objection was that there are restrictive connection rules.
• Supreme Court's ruling in Janus v.

Bills: SB75, SB715, SB776, SB1299, SB1405, SB1968, SB2021, SB2077, SB2148, SB2321, SB2330, SB2411

Keywords: electric generation, reliability, ERCOT, Public Utility Commission, penalties, performance requirements, energy policy, construction contracts, compensatory damages, government delays, contractor, legislation, nonprofit donor privacy, membership lists, supporter confidentiality, volunteer privacy, association rights, public records exemption, Texas Public Information Act, government transparency

Transcript Highlights:

• to do is allow regulatory capture for a couple of big players to come in here and set up a bunch of rules
• You know, on the transmission system, the rules for putting power on the grid or selling a reduction
• On the distribution system, the rules need to be clarified.
• The next big objection was that there are restrictive interconnection rules.
• Supreme Court's ruling in Janus v.

Bills: SB75, SB715, SB776, SB1299, SB1405, SB1968, SB2021, SB2077, SB2148, SB2321, SB2330, SB2411

Keywords: electric generation, reliability, ERCOT, Public Utility Commission, penalties, performance requirements, energy policy, construction contracts, compensatory damages, government delays, contractor, legislation, nonprofit donor privacy, membership lists, supporter confidentiality, volunteer privacy, association rights, public records exemption, Texas Public Information Act, government transparency

Summary: The Senate Committee on Business and Commerce heard Senate Bill 2021 by Senator Johnson, as substituted, on distributed energy resources (DERs). Johnson said the bill was intended to create a regulatory framework for DERs and virtual power plants, address interconnection and registration issues, and prevent regulatory capture as the industry grows. Testimony was split: Texas Electric Cooperatives asked for clarification so co-ops would not be unintentionally excluded from owning or operating DERs; AECT supported the bill as providing needed rules and customer protections; TABA, Texas Solar and Storage Association, Sierra Club, Texas Solar Energy Society, and several others opposed it or raised concerns that it was too utility-centric, imposed red tape, and could burden homeowners and small businesses with registration and interconnection requirements. Johnson repeatedly said the bill was not meant to stop rooftop solar or backup systems and that he was open to specific redlines and further changes. SB 2021 was left pending after testimony. The committee then took up Senate Bill 2330 by Senator Parker, which would end government payroll deduction for dues to certain public employee organizations, while exempting first responders under Chapters 143 and 147 and making other conforming changes in a committee substitute. Parker argued the bill was about government neutrality, transparency, and employee freedom from coercion, and said organizations can collect dues directly using modern payment methods. Supporters from Texas Public Policy Foundation, Texas Business Coalition, Freedom Foundation, ABC Texas, and Texans for Fiscal Responsibility said taxpayer-funded payroll systems should not be used to collect dues for private organizations, especially ones involved in political activity. Opponents, including ATPE, Texas Classroom Teachers Association, Texas Public Employees Association, and correctional employees, said payroll deduction is a convenient, secure service that helps professional associations and employee groups, and argued the bill would burden teachers and other public employees. Several witnesses and senators focused on the bill’s exemptions and whether it treated teachers differently from first responders. Senator Menendez questioned why some public employees were excluded while others were not, and a Houston police union representative said he moved from opposing to supporting the bill after being told the substitute would preserve meet-and-confer deductions under Chapters 143 and 147. Senator Parker closed by saying the bill was not meant to eliminate associations or payroll deduction entirely, only to remove the state as a middleman. SB 2330 was left pending, and the committee then recessed subject to call.

Transcript Highlights:

• SCOTUS has upheld, in multiple rulings, the privacy right of donors to nonprofit causes.
• In 1958, the Supreme Court ruled that the state of Alabama could not force the NAACP to disclose its
• In 1958, the Supreme Court ruled that the state of Alabama could not force the NAACP to disclose its
• 2005, and was never able to fully implement those rules.
• We do not have rules in place that deal with electromagnetic impulses.

Bills: SB75, SB715, SB776, SB1299, SB1405, SB1968, SB2021, SB2077, SB2148, SB2321, SB2330, SB2411

Keywords: electric generation, reliability, ERCOT, Public Utility Commission, penalties, performance requirements, energy policy, construction contracts, compensatory damages, government delays, contractor, legislation, nonprofit donor privacy, membership lists, supporter confidentiality, volunteer privacy, association rights, public records exemption, Texas Public Information Act, government transparency

Summary: The committee first took up pending business and favorably reported several bills without objection or by recorded vote, including SB 783, SB 1238, SB 1706, SB 1791, SB 458, SB 1644, and SB 1810, with some of them also sent to the local and uncontested calendar. The committee then moved into hearings on additional bills. SB 1968, by Senator Schwertner, would update the Real Estate License Act by repealing subagency, requiring written buyer-agent agreements before showings, and clarifying when a formal buyer representation agreement must be signed. Texas Realtors testified in support, saying the bill modernizes agency rules and increases transparency, while a committee substitute corrected drafting issues. SB 2411, the annual update to the Texas Business Organizations Code, was also laid out and left pending after supportive testimony from the Texas Business Law Foundation and drafting committee representatives. The committee also heard SB 2321, which would codify ERCOT’s current practice of notifying TCEQ when backup generation needs enforcement discretion for grid reliability; Sierra Club and a chamber of commerce witness supported it with suggestions for clearer emissions reporting, and the bill was left pending. SB 2077 would broaden eligibility for the Texas Mutual Insurance Company board by narrowing conflict restrictions tied to insurance-related interests; Texas Mutual supported the change and the bill was left pending. SB 1405, a broadband bill, would align state law with FCC standards and streamline Broadband Development Office processes; it was left pending after supportive testimony. SB 1299, protecting nonprofit donor privacy, drew support from privacy advocates and concerns from one witness about transparency for publicly funded nonprofit operations; it was left pending. The committee then heard SB 776, which would bar government construction contracts from shifting delay damages to contractors when delays are caused solely by the public owner. Contractors, surety representatives, and water infrastructure advocates supported the bill, arguing it would improve fairness and reduce inflated bids, while water utilities and critical infrastructure entities opposed it, warning of more litigation and higher costs; the bill was left pending. Finally, SB 715, which would apply reliability requirements retroactively to all generation resources in ERCOT, drew opposition from renewable and storage groups and support from some critics of renewable subsidies, with witnesses split over whether it would improve reliability or raise costs; testimony was underway when the transcript ended.

Transcript Highlights:

• University of Alabama as attends the University of Alabama as attends the University of Alabama as interning
• for Senator or and Senator Al interning for Senator or and Senator Al interning for Senator or and Senator
• President senat Wagner have a Wagner Mr President senat Wagner have a report from the committee on rules
• all report from the committee on rules all report from the committee on rules all right secretary R
• from the committee on rules Senate from the committee on rules Senate resolution number 15 special order

Bills: SJR 36, SJR 2, SB 4, SR 45, SR 47, SR 63, SR 66, SR 70, SR 85, SCR 14, SB 10, SB 11, SB 10, SB 11

Keywords: SJR 2, Senate Joint Resolution 2, constitutional amendment, homestead exemption, property tax relief, school property tax, ad valorem tax, residence homestead, school district taxes, Texas Constitution Article VIII, public school finance, homeowner exemption, elderly exemption, senior tax relief, disabled exemption, tax year 2025, voter approval, November 2025 ballot, local government, Ways & Means

Transcript Highlights:

• And then finally, one of our staffers up there, our intern Hales from DeWitt County, and I've...

Bills: SJR36, SJR2, SB4, SR45, SR47, SR63, SR66, SR70, SR85, SCR14, SB10, SB11, SB10, SB11

Keywords: SJR 2, Senate Joint Resolution 2, constitutional amendment, homestead exemption, property tax relief, school property tax, ad valorem tax, residence homestead, school district taxes, Texas Constitution Article VIII, public school finance, homeowner exemption, elderly exemption, senior tax relief, disabled exemption, tax year 2025, voter approval, November 2025 ballot, local government, Ways & Means

Transcript Highlights:

• Houston himself who sent a diplomatic mission... to London nearly two centuries ago, securing international
• history with the U.K. and our... common values of entrepreneurial spirit, freedom, and respect for the rule
• This caucus will be at the forefront of the Texas and U.K. partnership and international cooperation,
• Claudia Tan, just about a year ago, I experienced firsthand how committed Texans are to supporting international

Bills: SJR36, SJR2, SB4, SR45, SR47, SR63, SR66, SR70, SR85, SCR14, SB10, SB11, SB10, SB11

Keywords: SJR 2, Senate Joint Resolution 2, constitutional amendment, homestead exemption, property tax relief, school property tax, ad valorem tax, residence homestead, school district taxes, Texas Constitution Article VIII, public school finance, homeowner exemption, elderly exemption, senior tax relief, disabled exemption, tax year 2025, voter approval, November 2025 ballot, local government, Ways & Means

Transcript Highlights:

• TO APPROPRIATE FUNDS TO ENSURE LAW ENFORCEMENT HAS SUFFICIENT RESOURCES TO UPHOLD AND ENFORCE THE RULE
• Senate President Albritton: MADAM RULES CHAIR, YOU ARE RECOGNIZED FOR A MOTION. THANK YOU, MR.
• Senate President Albritton: THANK YOU, MADAM RULES CHAIR.
• MADAM RULES CHAIR, YOU ARE RECOGNIZED FOR ANOTHER MOTION. THANK YOU, MR. PRESIDENT.
• MADAM RULES CHAIR PASSIDOMO, YOU ARE RECOGNIZED FOR A MOTION. THANK YOU, MR. PRESIDENT.

Bills: SJR36, SJR2, SB4, SR45, SR47, SR63, SR66, SR70, SR85, SCR14, SB10, SB11, SB10, SB11

Keywords: SJR 2, Senate Joint Resolution 2, constitutional amendment, homestead exemption, property tax relief, school property tax, ad valorem tax, residence homestead, school district taxes, Texas Constitution Article VIII, public school finance, homeowner exemption, elderly exemption, senior tax relief, disabled exemption, tax year 2025, voter approval, November 2025 ballot, local government, Ways & Means

Transcript Highlights:

• federal rule itself. federal rule itself.
• The alignment between the federal rule and then state rule.
• this rule. I understand the connection. this rule. I understand the connection.
• internal governance than anything else. internal governance than anything else.
• established by the board by rule. established by the board by rule.

Bills: SB2607, SB2031, SB2043, SB2623, SB2876, SB2396, SB2964, SB2089

Keywords: landscape architecture, licensure, educational requirements, examination, professional standards, consumer protection, junk fees, live-event tickets, short-term lodging, transparency, pricing disclosure, deceptive practices, insurance, captives, regulations, policyholders, SB2623, Hawaii pharmacy law, Board of Pharmacy, registered pharmacy technician

Summary: The committee first heard HCR 168 and HR 158, which would create a temporary working group to study utility capacity, coastline infrastructure lifespan, and the costs of needed expansions. Public Utilities Commission staff said the commission was not the right entity to direct all of the work because it lacks authority over many affected agencies. Members discussed whether the study should be limited to a coastal area or broadened to the whole island, and in decision-making the committee amended the measure to focus on the County of Honolulu, correct references to the Public Utilities Commission, and revise the working group membership to include the PUC chair, legislative designees, and directors or designees from DLNR, DOT, HIEMA, and DCCA Consumer Advocacy. The committee then passed both resolutions with amendments; the vote was adopted unanimously, with some members excused. The committee next considered HCR 145 and HR 137, which would convene a working group on climate change impacts on insurance availability and affordability. The Insurance Division stood on its written comments, the Climate Change Mitigation and Adaptation Commission supported the intent, and the Attorney General opposed the measure, warning that a working group could create discoverable materials that might complicate the state’s climate litigation and noting a technical ambiguity in the reference to the Hawaii Hurricane Relief Fund administrator. After questions about discovery and the lawsuit, the committee amended the resolutions to replace the administrator reference with the chair of the Hawaii Hurricane Relief Fund Board of Directors, remove the Attorney General as convener while keeping the office as a member, and have the working group share findings and recommendations with the House CPC and Senate CPN committees instead of issuing a report. The committee passed the measures with amendments, with Rep. Martin voting with reservations. In the later agenda, the committee heard SB 2607, SD 1 on landscape architect licensure. The Board of Professional Engineers, Architects, Surveyors, and Landscape Architects supported the bill, explaining it modernizes licensure requirements to align with national standards and clarifies the profession’s design-focused role. The bill was discussed as distinguishing landscape architecture from groundskeeping and from civil engineering drainage work. No opposition was heard. The committee also heard SB 2031, SD 2 on consumer protection and price transparency for live ticket events and short-term lodging. The Office of Consumer Protection supported the bill, saying it largely mirrors an FTC rule requiring all-in pricing and would give the state enforcement authority and remedies. The Hawaii Financial Services Association opposed the bill as drafted and sought a limited exemption for credit card issuers relying on third-party hotel information, while the Hawaii Hotel Alliance supported the measure but asked for language deeming compliance with the federal rule sufficient for short-term lodging. Committee members questioned whether those proposed exemptions would conflict with federal law or weaken state enforcement, and the discussion focused on preemption, liability, and the value of state remedies such as restitution.

Transcript Highlights:

• There needs to be guidelines, rules, I don't know how else to put it.
• worked with the governor's office for a number of years to request a waiver to the CMS exclusionary rule
• . ...to request a waiver to the CMS exclusionary rule that would allow for funding to be used for reentry
• county or a city rejects it entirely, With when a county or a city rejects it entirely, after the ruling
• with Acre 41 the Department of Health Services in 2021, and at that point in time I knew that the rules

Bills: SB1071, SB1315, SB1317, SB1416, SB1493, SB1537, SB1542, SB1584, SB1626, SB1740, SB1751, SB1804, SCR1047, SCR1049

Keywords: Arizona Rangers, statutory repeal, security, state law, regulatory changes, school safety, interoperable communications, law enforcement, emergency response, funding, reentry programs, criminal justice, grants, recidivism, attorney general, missing children, kidnapping, reporting requirements, child safety, training

Summary: The committee first took up SB 1071, which would repeal the statutory framework for the Arizona Rangers. The sponsor argued the bill was about accountability and transparency, citing concerns about missing training and firearms qualification records; Arizona Rangers representatives and several sheriffs opposed the bill, saying the Rangers provide valuable volunteer support and that the real issue was adding oversight rather than eliminating protections. After discussion, the committee voted 4-3 to give SB 1071 a do pass recommendation, with members noting they expected amendments later. The committee then heard SB 1315, requiring school districts and charter schools to maintain interoperable emergency communications with law enforcement and to submit annual affidavits confirming testing and compliance. Testimony from school safety officials and sheriffs emphasized the value of real-time communication during emergencies and the need for secure sharing of campus maps and floor plans; concerns about cost and information security were addressed by supporters. The bill passed unanimously, 7-0. The committee also advanced SB 1317, which appropriates opioid settlement funds for county reentry planning programs; sheriffs and association representatives supported it, citing reduced recidivism and jail populations, and it passed 7-0. Several public safety and missing-children measures were considered next. SB 1416, as amended, revises missing child reporting requirements, adds runaway children back into reporting, requires faster photo and information sharing, and expands training requirements; advocates for missing children and law enforcement supported the compromise language, and the bill passed 7-0. SB 1740, which updates Turquoise Alert training and procedures, was also advanced 7-0 after discussion about statewide versus geographically targeted alerts and the need to keep alerts effective. Later, SB 1493, a strike-everything amendment affecting police officer termination appeals and fee shifting when an employer rejects a favorable administrative ruling, passed 5-2 despite opposition from chiefs’ representatives. SB 1537, renaming the Peace Officer Training Equipment Fund and repealing its advisory commission, passed 5-2. The committee also approved SB 1751 and SCR 1049, which expand execution methods to include lethal gas and firing squad and make firing squad mandatory in certain cases involving the murder of a law enforcement officer; opponents raised constitutional, ethical, and practical concerns, while supporters framed the measures as aligning Arizona with other states and providing additional options. Both measures passed 4-3. Finally, SB 1542, which would create a framework and funding for MDMA research and treatment for PTSD in first responders and peace officers contingent on FDA approval, was heard with testimony describing promising clinical trial results and the need for Arizona research; the bill was then moved forward, though the transcript cuts off before the final roll call result is fully shown.

Transcript Highlights:

• , uh, license commissions and agencies are self-declaring an emergency so they can write emergency rules
• <00:04:30.080> and<00:04:30.320> kind<00:04:30.479> of write emergency rules
• [laughter] >> You need to take me before Internal Affairs. >> I uh... >> So is it saying that um the
• [laughter] >> You need to take me before internal affairs.
• >> You need to take me before internal >> You need to take me before internal affairs

Bills: HB136, HB137, HB220, HB213, HB256, HB136, HB137, HB220, HB213, HB256

Keywords: Teacher's Retirement System, TRS, DROP, Deferred Retirement Option Plan, retirement benefits, teacher retirement, classroom teacher, Tier I, Tier II, public pension, pension reform, education employees, retirement system, sick leave, cost-of-living adjustment, COLA, beneficiary, lump-sum payout, rollover, service retirement